Standard Decoration Contract Sample Reference Caution Trap
The decoration is a relatively rigorous thing, often before signing a contract. This decoration contract is a contract signed according to the "Contract Law of the People's Republic of China" and related laws and regulations for the purpose of house decoration. And the decoration contract also has a certain format, everything should be carried out in accordance with the contents of the contract. How is the signing of the decoration contract in the end? When signing a decoration contract, what issues should be used to pay attention? Let's take a look together. Decoration contract sample Contract No:________ Employer: Contractor: Attorney: Business License No.: Telephone: Attorney: Telephone: In accordance with the "Contract Law of the People's Republic of China" and relevant laws and regulations, combined with the characteristics of the construction and decoration of family homes, both parties negotiated on the basis of the relevant issues concerning the contractor's family room renovation project (hereinafter referred to as "the project"). , reached the following agreement: The first project overview 1.1 Project location: ______________________________________. 1.2 Project Contents and Practices (Family Room Decoration Project Construction Project Budget Statement). 1.3 Project contracting methods: Both parties agreed to adopt the following ______ contracting methods. (1) contractors, contractors, materials; (2) The contractor includes contractors and part of the materials (the contractor provides the decoration materials list), and the contractor provides some materials (the contractor provides the decoration materials); (3) the contractor and the contractor package materials (the contractor provides Decoration materials schedule). 1.4 The construction period is ________ days, the construction date is ________ years_____months, and the completion date is ______ years____months__. 1.5 Contract price: The construction cost of this contract is (in uppercase): ________________________$, lowercase: ______________$ (quotations for home decoration and decoration projects). The second project supervision If this project implements project supervision, the contractor and the supervision company shall sign the "project supervision contract" separately, and notify the contractor of the name, unit, contact information and supervision engineer's duties of the supervision engineer. Third construction drawing The parties agreed to provide the following drawings in the following ______ ways: (1) The Employer shall design and provide the construction drawings on its own, and the drawings shall be in duplicate, and the contractor and the contractor shall each have one copy (see the design drawing of the family room decoration and decoration project for details); (2) The Employer entrusts the Contractor with the design and construction drawings. The drawings shall be in duplicate, the contractor and the contractor shall each have one copy (see the design drawing of the family room decoration and decoration project for details), and the design fee (in capital) ____________Yuan shall be paid by the Employer. (This fee is not included in the project price). Article 4 Obligations of the Employer 4.1 ________ days before construction, to create conditions for the contractor to enter the construction. Including: removal of furniture, furnishings, furniture or furnishings that are not easy to move in the room, as well as collection and concealment, so as not to affect the construction principle; 4.2 Provide water and power during construction; 4.3 Responsible for coordinating the relationship between the construction team and its neighbors; 4.4 Do not remove the indoor load-bearing structure. If it is necessary to dismantle the non-load-bearing structures or equipment pipelines of the original building, it is responsible for going through the relevant approval procedures for the relevant departments; 4.5 During the construction period, the contractor still needs to use the room in part, and is responsible for doing a good job of security and fire protection at the construction site. 4.6 Participate in the supervision of project quality and construction progress. Responsible for material entry and acceptance. Article 5 Obligations of Contractors 5.1 Strictly implement the safety construction operation rules, fire prevention regulations, construction specifications and quality standards during construction, and complete the project on schedule; 5.2 Strict implementation of the provisions on the management of the construction site shall not disturb the people and pollute the environment; 5.3 Protect the furniture and furnishings of the interior of the original room to ensure the smooth flow of the upper and lower water pipes in the room; 5.4 Ensure the cleanliness of the construction site, and clean the construction site after the completion of the project. Article 6 Project Changes If the project and construction method need to be changed, the two parties shall negotiate and agree on a written change agreement (or change the project budget), and adjust the related project cost and construction period (must guarantee the use of 100 square meters of housing paint and latex paint project 25- 30 days, installation works 5-10 days). Article 7 Provision of Materials 7.1 Materials and equipment provided by the contractor. The contractor shall notify the contractor before the materials are delivered to the construction site, and both parties shall jointly accept and handle the handover procedures. 7.2 Materials and equipment provided by the contractor (the contractor shall provide the decoration materials list). The contractor shall notify the contractor before the material is delivered to the construction site and accept the inspection by the contractor. Article 8 Delays in duration 8.1 Delay in the completion date for the following reasons is confirmed by the Employer and the duration of the construction period is correspondingly extended: (1) Changes in engineering quantities and design changes; (2) The contractor agrees that the duration of the project will be postponed. 8.2 If the contractor does not affect the construction period due to the contractor's failure to perform the work he is responsible for, the construction period will be postponed. If the quality of the materials and equipment provided by the contractor is unqualified and the quality of the project is affected, the cost of the rework will be borne by the contractor and the duration of the project will be postponed. 8.3 The contractor failed to pay the project payment on schedule (within three days after the signature of the acceptance certificate), and the duration will be extended accordingly. 8.4 If the contractor's responsibility can not be implemented on schedule or the stoppage of the work stoppage due to unreasonable midway stoppage, the construction period will not be postponed. If there is a problem with the quality of the project due to the contractor's reasons, the specific rectification plan shall be proposed by Party A or Party A within three days. The cost of rework is borne by the contractor and the duration of the consultation is postponed. The second rectification period for the same quality problem will not be postponed. Article 9 Quality Standard The two parties agreed on the construction quality standard of the project: <Code for the construction of residential decoration works GB 50327-2001>. During the construction process, both parties disputed the quality of the project. The competent department of the Wuhan Decoration Association certified the quality of the project. The quality of the certified project did not meet the requirements. The contract stipulated standards and related expenses incurred in the certification process shall be borne by the contractor; the quality of the certified project shall comply with the standards stipulated in the contract, and the expenses incurred in the certification process shall be borne by the contractor. Article 10 Project Acceptance and Warranty 10.1 The two parties agreed to check the quality of the project in the following stages during the construction process: (1)_________________________; (2)_________________________; (3) _________________________. The contractor shall inform the contractor two days in advance of the acceptance. After acceptance of the phase, the project acceptance checklist shall be completed (see Attached Table 8: Acceptance slip for the family room decoration project). 10.2 After completion of the project, the contractor shall notify the contractor for acceptance. The contractor shall organize acceptance within two days after receipt of the acceptance notice and complete the project acceptance checklist (see Attached Table 8: Acceptance Form for Domestic Home Decoration Project). After the construction section is settled, the transfer formalities will be handled (for details, please refer to Table 9: Settlement and Settlement of Family Homes). 10.3 The warranty period for this project is _____ months from the date of acceptance by both parties. Acceptance of the signing of the acceptance, fill out the project warranty (see the attached table 10: family home decoration repair warranty). Article 11 Payment Methods 11.1 The two parties agreed to pay the project payment in the following _____ way: (1) After the contract becomes effective, the contractor shall directly pay the contractor the project money as stipulated in the following table: | Payments | Payments | Payments | | First | 3 days before starting | Payment | | Second time | More than half of the project progress | Paying yuan | | Third | Accepted by both parties | Paying yuan | More than half of the progress of the project means: ____________________________________. (2) Other payment methods: __________________________________. 11.2 After the acceptance of the project is completed, the contractor shall submit the settlement to the contractor and send the relevant information to the contractor. If the developer has no objection within ____ days after receiving the information, he shall be deemed to have agreed and the two parties shall complete the project settlement statement (see Attached Table 9: Settlement and Decoration of Family Room Decoration Project) and sign it. The contractor settled the end of the project. 11.3 After the construction funds are fully settled, the contractor shall issue a formal unified invoice to the contractor. Article 12 Liability for breach of contract 12.1 Each of the parties to the contract shall be liable by the responsible party for any failure to perform the contractual stipulations or violations of the national laws, regulations and relevant policies, and shall compensate the other party for the economic loss caused by the penalty. 12.2 The contractor shall be responsible for any loss caused by the failure to apply for acceptance procedures or unauthorized use of the finished product. 12.3 If for any reason the contract cannot be performed, the party shall promptly notify the other party to complete the contract termination procedure and the responsible party shall compensate the other party for the corresponding economic loss. 12.4 If the Employer fails to pay the second (three) project payment on time, he shall pay the counterparty ____yuan per delay for one day. 12.5 Due to the contractor's reasons, the quality of the project cannot meet the quality standards agreed by both parties. The contractor is responsible for the repair and the construction period will not be postponed. 12.6 Due to delays in the construction period due to the contractor's reasons, the liquidated damages shall be paid to the other party for every one day's delay. Article 13 Contract Dispute Resolution The disputes arising during the performance of this contract shall be settled through negotiation between the parties concerned; they may also be settled by the relevant departments; if the negotiation or mediation fails, the following ___________________________________ (1) Submit ________ Arbitration Commission Arbitration; (b) to sue the people's court in accordance with the law. Article 14 Specific Provisions 14.1 The garbage generated due to construction will be transported out of the construction site by the contractor and transported to the designated location. The contractor is responsible for paying the clean freight (capital) ________ yuan (This fee is not included in the project price) . 14.2 During the construction period, the contractor will give the outside house key ____ to the contractor for safekeeping. After the acceptance of the project is completed, the contractor is responsible for providing the new lock ____, which will be delivered on the spot by the contractor. 14.3 During the construction period, the contractor's daily working hours are: ________ minutes to _____ points in the morning and _____ points to ___ points in the afternoon. Article 15 Other Matters Article 16 Supplementary Provisions 16.1 This contract shall become effective after both parties have signed (stamped) the contract and shall be terminated upon completion of the contract. 16.2 The project shall not be subcontracted after this contract is signed. 16.3 This contract has _____ copies, each party holds ____ copies and ___________ departments have ____ copies. 16.4 The contract attachment is an integral part of the contract and has the same legal effect as this contract. contract attachment Schedule 1-1: Confirmation Form for Construction Project of Family Room Decoration Project (1) Schedule 1-2: Confirmation Form for Construction Project of Family Room Decoration Project (2) Attached Table 2: List of Contents and Practices of Family Room Decoration Project Attached Table 3: Home House Decoration Project Quote Schedule 4: List of Decoration Materials Provided by the Employer Schedule 5: List of Decoration Materials Provided by the Contractor Schedule 6: Design Drawings for Family Home Decoration Attached Table 7: Family Room Decoration Decoration Change Order Attached Table 8: Acceptance Form for Family Room Decoration Project Schedule 9: Settlement and Settlement Statement for Family Room Decoration Schedule 10: Family Room Decoration Repair Warranty Employer (signature): Contractor (seal): Legal representative: Attorney: Year Month Day Year Month Day Editor's summary: The above is the standard decoration contract sample reference caution trap related to the introduction, hoping to help meet the needs of friends! For more information, please continue to pay attention to our website, follow-up will show more exciting content. How to avoid renovation contract trap decoration trap decoration contract decoration find decoration company okay decoration materials brand Tape Measure,Tape Measure Steel,Household Measuring Tools,Sewing Tape Measure Yucheng Weisite Measuring Tools Co., Ltd , https://www.wsttools.com